Terms of service

Terms of Service

Terms & Conditions

By purchasing products or services from our company, the customer agrees to the following Terms & Conditions.

1. General

We reserve the right to refuse service, cancel orders, or deny warranty claims at our sole discretion.

All products, pricing, specifications, lead times, and availability are subject to change without notice.

2. Custom Fabrication & Off-Road Use

Many of our products are:

  • Custom fabricated
  • Modified
  • Performance-oriented
  • Intended for off-road use only

Customer understands that vehicle modifications may affect:

  • Vehicle handling
  • Safety
  • Ride quality
  • Manufacturer warranties
  • Emissions compliance
  • Road legality

It is the customer’s responsibility to verify compliance with local, state, and federal laws before installation or use.

3. Off-Road Use Only Disclaimer

Products labeled “Off-Road Use Only” are not intended for use on public highways unless specifically stated otherwise.

Customer assumes all responsibility and risk associated with installation and use of modified or fabricated components.

4. Assumption of Risk

Customer acknowledges that fabrication, vehicle modification, suspension modification, off-road driving, towing, racing, and performance applications involve inherent risks.

By purchasing or using our products, customer voluntarily assumes all risks including:

  • Property damage
  • Vehicle damage
  • Mechanical failure
  • Personal injury
  • Death

5. Limitation of Liability

To the fullest extent permitted by law, we shall not be liable for:

  • Indirect damages
  • Consequential damages
  • Loss of use
  • Lost profits
  • Labor costs
  • Installation/removal costs
  • Vehicle downtime
  • Personal injury
  • Property damage
  • DEATH

Our maximum liability shall never exceed the original purchase price of the product or service provided.

6. No Warranty on Misuse or Competition Use

No warranty is provided for products subjected to:

  • Abuse
  • Misuse
  • Neglect
  • Improper installation
  • Racing
  • Competition use
  • Overloading
  • Accidents
  • Alteration or modification after sale

Improper installation voids all warranties.

7. Customer Responsibility

Customer is responsible for:

  • Verifying fitment before purchase
  • Ensuring proper installation
  • Using qualified installers when necessary
  • Routine inspection and maintenance
  • Safe operation of the vehicle and products

We are not responsible for damages caused by improper installation or use.

8. Fabrication Variations

Due to the handmade and fabricated nature of our products:

  • Minor cosmetic imperfections may occur
  • Dimensions may vary slightly
  • Weld appearance may vary
  • Finish variations may occur

These are normal characteristics of custom fabrication and do not constitute defects.

9. Lead Times & Delays

Estimated production and shipping times are estimates only and are not guaranteed.

We are not liable for delays caused by:

  • Supply chain issues
  • Material shortages
  • Freight carriers
  • Vendor delays
  • Labor shortages
  • Weather
  • Events beyond our control

10. Deposits & Payments

Deposits on custom orders are non-refundable once materials are purchased or fabrication has begun.

Failure to complete payment may result in:

  • Project delays
  • Storage fees
  • Cancellation of the order

Unpaid balances may be subject to collections and legal fees.

11. Returns & Cancellations

Custom fabricated products are non-returnable and non-refundable.

Returns on approved standard items may be subject to:

  • Restocking fees
  • Return shipping costs
  • Inspection approval

Used, installed, modified, damaged, or special-order items are not eligible for return.

12. Shipping & Freight

All shipping terms are governed by our Shipping & Freight Policy.

Customer is responsible for inspecting shipments upon delivery and reporting freight damage immediately.

13. Chargebacks & Payment Disputes

Customer agrees to contact us directly to resolve disputes before initiating chargebacks or payment reversals.

Fraudulent or unjustified chargebacks may result in:

  • Collections action
  • Legal action
  • Recovery of attorney fees
  • Recovery of administrative costs

14. Intellectual Property

All designs, fabrication methods, product names, logos, photos, and content remain our property and may not be copied or reproduced without written permission.

15. Installation & Mechanical Disclaimer

We are not responsible for:

  • Alignment issues
  • Tire wear
  • Suspension geometry changes
  • Vibration
  • Noise
  • Driveline wear
  • Compatibility with aftermarket parts

Professional installation is strongly recommended.

16. Indemnification

Customer agrees to defend, indemnify, and hold harmless our company, owners, employees, and affiliates from any claims, damages, losses, liabilities, or legal expenses arising from:

  • Product use
  • Installation
  • Vehicle modifications
  • Negligence by customer or installer
  • Off-road or competition use

17. Governing Law

These Terms & Conditions shall be governed by the laws of the state in which our business operates.

Any disputes shall be resolved in the courts located within that state.

18. Acceptance of Terms

By purchasing products or services from us, customer acknowledges they have read, understood, and agreed to these Terms & Conditions in full.

You should also consider adding these as separate documents:

  • Warranty Policy
  • Installation Disclaimer
  • Off-Road Use Waiver
  • Fabrication Estimate Terms
  • Shop Storage Policy
  • Vehicle Abandonment Policy
  • Customer-Supplied Parts Disclaimer

I can also make:

  • a shorter website version,
  • an aggressive “maximum protection” version,
  • a cleaner professional version,
  • or a customer invoice/receipt version that fits on one page.


installation policy , fab estimate terms, and customer supplied parts.

Installation Policy

Installation Terms & Conditions

By authorizing installation work, customer agrees to the following terms:

1. Vehicle Condition

Customer confirms the vehicle is in safe operating condition prior to service.

We are not responsible for pre-existing:

  • Mechanical problems
  • Electrical issues
  • Rust or corrosion damage
  • Broken hardware
  • Previous poor workmanship
  • Hidden damage

Additional repairs required during installation will result in additional charges.

2. Labor & Fabrication Charges

All labor charges are based on estimated shop time. Actual labor time may vary due to:

  • Rusted or seized hardware
  • Previous modifications
  • Broken bolts
  • Fitment issues
  • Wiring complications
  • Hidden damage

Additional labor required beyond the original estimate will be billed accordingly.

3. Custom Fabrication Adjustments

Custom fabrication often requires:

  • Trimming
  • Grinding
  • Welding
  • Drilling
  • Cutting
  • Modification of factory components

Customer acknowledges permanent modifications may be required during installation.

4. No Guarantee on Ride Quality or Performance

Modified vehicles may experience:

  • Increased noise
  • Vibration
  • Harshness
  • Alignment changes
  • Tire wear
  • Reduced ride comfort

We do not guarantee ride quality, drivability, or compatibility with other aftermarket parts.

5. Alignment & Re-Torque Responsibility

Customer is responsible for:

  • Alignment after suspension or steering modifications
  • Re-torque inspections after initial use
  • Routine maintenance and inspection

Failure to perform required maintenance may result in component failure.

6. Customer-Supplied Parts

No warranty is provided on customer-supplied parts.

We are not responsible for:

  • Incorrect parts
  • Defective parts
  • Missing hardware
  • Delays caused by customer parts
  • Additional labor caused by poor fitment

Additional labor charges may apply.

7. Test Driving

Vehicles may be test driven as necessary for:

  • Diagnostics
  • Calibration
  • Verification of repairs
  • Alignment checks

8. Storage Fees

Vehicles left over 7 days after completion may be subject to daily storage fees unless prior arrangements are made.

9. Limitation of Liability

We are not liable for:

  • Vehicle downtime
  • Loss of use
  • Towing charges
  • Rental expenses
  • Lost income
  • Consequential damages

10. Acceptance

By approving work, customer agrees to all installation terms and conditions.

Fabrication Estimate Terms

Fabrication Estimate Terms & Conditions

All estimates provided are subject to the following terms:

1. Estimates Are Approximate

Fabrication estimates are based on projected labor, materials, and shop time.

Actual final cost may vary due to:

  • Design changes
  • Material price fluctuations
  • Hidden issues
  • Additional labor
  • Customer-requested modifications

2. Custom Work

All fabrication work is custom in nature and may require adjustments during the build process.

Customer acknowledges final products may vary slightly from:

  • Drawings
  • Photos
  • Renderings
  • Verbal descriptions

3. Deposits

Deposits are non-refundable once:

  • Materials are ordered
  • Design work begins
  • Fabrication has started

4. Change Orders

Any customer-requested changes after approval may result in:

  • Additional labor charges
  • Material charges
  • Delays in completion

Verbal approvals may be treated as authorization to proceed.

5. Material Pricing

Steel, aluminum, hardware, coatings, and freight pricing are subject to market fluctuations.

Quoted pricing may change if material costs increase before fabrication begins.

6. Lead Times

Estimated completion dates are not guaranteed.

Delays may occur due to:

  • Material shortages
  • Supplier delays
  • Equipment failure
  • Shop workload
  • Design revisions

7. Storage & Abandoned Projects

Completed projects not picked up within 14 days may incur storage fees.

Projects abandoned for extended periods may become subject to mechanic’s lien procedures where permitted by law.

8. Cancellation

Custom fabrication orders may not be canceled once production begins.

Customer is responsible for labor and material costs incurred up to cancellation date.

9. Ownership of Designs

All shop-built designs, jigs, fixtures, CAD files, and fabrication methods remain our property unless otherwise agreed in writing.

10. Acceptance

Approval of an estimate constitutes acceptance of these terms and conditions.

Customer-Supplied Parts Policy

Customer-Supplied Parts Terms

We allow customer-supplied parts under the following conditions:

1. No Warranty

We provide no warranty, guarantee, or liability coverage on customer-supplied parts.

Any manufacturer warranty must be handled directly through the original supplier.

2. Fitment Responsibility

Customer is solely responsible for verifying:

  • Correct fitment
  • Compatibility
  • Completeness
  • Quality of supplied parts

We are not responsible for incorrect or incompatible parts.

3. Additional Labor Charges

Additional labor charges may apply for:

  • Poor fitting parts
  • Missing hardware
  • Defective components
  • Modifications required for installation
  • Repeat labor caused by failed customer parts

4. Used or Modified Parts

Used, damaged, modified, or secondhand parts are installed at customer’s risk.

We reserve the right to refuse installation of unsafe or low-quality components.

5. Delays

We are not responsible for delays caused by:

  • Incorrect parts
  • Shipping issues
  • Missing components
  • Warranty replacements

Additional shop time may be billed accordingly.

6. Removal & Reinstallation Costs

If a customer-supplied part fails, all labor associated with:

  • Diagnosis
  • Removal
  • Replacement
  • Reinstallation

will be billed to the customer.

7. Damage Liability

We are not responsible for damages resulting from:

  • Defective customer-supplied parts
  • Improperly manufactured components
  • Part failure after installation

8. Right to Refuse

We reserve the right to refuse installation of any customer-supplied parts at our discretion.

9. Acceptance

Providing customer-supplied parts for installation constitutes acceptance of these terms.